廣告禮品購銷契約 篇1
甲方：______________
乙方：______________
經甲、乙雙方協商，甲方向乙方定購以下商品。經雙方友好協商，訂製本契約條款如下：
一、品名、數量、價款。
品名：______________規格：______________
數量：______________單價：______________
金額：______________備註：______________
合計幣：__________________
二、按甲方要求，在產品上印刷LOGO方式為：____________。
三、製作周期______天。
四、結算方式及期限：本契約簽定之日甲方應向乙方支付該契約總金額的______%定金，金額為_______元人民幣，剩餘貨款甲方應在乙方貨到之日，驗收合格後一次付清全款。
五、交貨方式：______________；交貨時間：______________；交貨地點：______________ 。
六、契約生效後，乙方收取甲方定金後開始生產，如甲方中途改動設計，乙方有權推遲交貨期。
七、本契約一式兩份，雙方簽字蓋章方可生效，上述各項條款未盡事宜一律根據《中華人民共和國民法典》中相關規定執行。
甲方單位：______________
地址：______________電話：______________
傳真：______________ 網址：______________
信箱：______________委託人：______________
執照號碼：______________稅務登記號碼：______________
乙方單位：______________
地址：______________電話：______________
傳真：______________ 網址：______________
信箱：______________委託人：______________
執照號碼：______________稅務登記號碼：______________
廣告禮品購銷契約 篇2
甲方：______________ 乙方：______________
經甲、乙雙方協商，甲方向乙方定購以下商品。經雙方友好協商，訂製本契約條款如下：
一：品名、數量、價款。
品名：______________ 規格：______________
數量：______________ 單價：______________
金額：______________ 備註：______________
合 計 幣：__________________
三：按甲方要求，在產品上印刷LOGO方式為：____________
四：製作周期______天。
五：結算方式及期限：本契約簽定之日甲方應向乙方支付該契約總金額的______%定金，金額為_______元人民幣，剩餘貨款甲方應在乙方貨到之日，驗收合格後一次付清全款。
六：交貨方式：______________
交貨時間：______________
交貨地點：______________ 。
七：契約生效後，乙方收取甲方定金後開始生產，如甲方中途改動設計，乙方有權推遲交貨期。
八：本契約一式兩份，雙方簽字蓋章方可生效，上述各項條款未盡事宜一律根據《中華人民共和國民法典》中相關規定執行。
九：其他約定事項：
甲方 單位：______________
地址：______________ 電話：______________
傳真：______________ 網址：______________
信箱：______________ 委託人：______________
執照號碼：______________ 稅務登記號碼：______________
乙方單位：______________
地址：______________ 電話：______________
傳真：______________ 網址：______________
信箱：______________ 委託人：______________
執照號碼：______________ 稅務登記號碼：______________
廣告禮品購銷契約 篇3
Address:
Telephone：
Party B: Address:
Telephone：
According to the provisions of the contract law of the People's Republic of China and the relevant laws and regulations, Party B accepts the entrustment of the first party and entrustment with the two parties through consultation.
First, entrustment:
Two, the way of payment:
1, Party A shall pay 40% of the total cost of the contract, namely ____ yuan (RMB) to Party B, Party B received the money after the start of design.
2. Party B shall provide complete design draft. After confirmation by Party A, the total amount of the total cost shall be paid.
Three. Design time:
1, Party B shall provide complete design draft in __ working days.
2, Party B shall complete the design work of party a company commissioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).
Four. The responsibilities and obligations of the two parties:
1, Party B shall, according to the requirements of Party A to finish the related work on time.
2, Party A has the responsibility to fully cooperate with Party B to carry out the work stipulated in this contract and provide relevant information according to the needs of Party B. Party A is responsible for the consequences caused by Party A's delay in the required information.
3. Party A shall provide complete design information before the start of the design, due to Party A's provision of incomplete information and changes in content.
For structural changes, Party A shall pay the corresponding cost of design changes.
4. After Party B receives the complete design information of Party A, it is designed to facilitate the determination of the style of Party A, and Party B begins to design the first draft after the style is determined.
5, Party A has the right to put forward amendments to the works designed by Party B. The first draft Party A can make a structural modification. After the first draft is determined, the structural modifications should be made. Party A shall pay the corresponding cost separately.
6. The consequences of the delay due to the amendment of Party A shall be borne by Party A.
7, due to the loss caused by post production by Party A alone, the loss caused by problems in the design of the product is borne by Party B. The legal liability caused by copyright, for the economic disputes shall be borne by Party a..
8. During the course of the project, Party B is attached to the brand of Party A and shall not sign any form of cooperation agreement with the customer in the identity of Party B.
Five. The agreement on intellectual property rights:
1, Party B has the copyright of the works completed by the design. After the settlement of all the fees designed by Party A, Party B may transfer the copyright of the works to Party A.
2. Before Party A has not paid all the cost of the design, the copyright of the works designed by Party B shall be attributed to Party B, and Party A does not have any right to the work.
3. Party A shall have the right to investigate the legal liability of Party A if it uses or amends the works designed by Party B before the payment is not paid.
Six. Liability for breach of contract:
1, Party A terminates the contract before the completion of the first draft of the design work. The prepaid expenses have no right to request the return. If a party terminates the contract after the completion of the first draft of Party B's work, it shall pay the full design fee.
2. If Party B terminates the contract without proper reasons, the fees charged shall be returned to Party A.
Seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. If either party fails to negotiate, any Party A and B can submit it to the Beijing Arbitration Commission for arbitration.
Eight, the contract is effective from the date of signature by Gai Zhang and both parties. The contract is two copies in one form. Each party has one contract signed by the other party (Gai Zhang), which has the same legal effect.
Nine. If there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. The contents of the supplement and modification are equally valid to this contract.
Party A: Party B:
(signature seal) (signature seal)
Date: Date:
中文版
地址：
電話：
乙方：地址：
電話：
依據《中華人民共和國契約法》和有關法規的規定，乙方接受甲方的委託，就委託設計事項，雙方經協商一致，簽訂本契約，信守執行：
一、委託事項：
二、付款方式：
1、甲方需在契約簽訂之時支付總費用的40% ，即____元(人民幣)給乙方，乙方收到甲方的款項後開始設計。
2、乙方提供完整的設計稿，甲方確認後,應當即付清總費用的全部餘款。
三、設計時間：
1、乙方需在__個工作日內提供比較完整的設計稿。
2、乙方需在_____年__月__日完成甲方公司委託的設計工作 (由甲方原因耽誤的時間，完稿時間應順延)。
四、雙方的責任與義務：
1、乙方應按甲方要求按質按量按時完成相關設計工作。
2、甲方有責任全力配合乙方開展本契約所規定的工作，並根據乙方需要提供相關資料。由於甲方提供所需資料延誤時間造成的後果，由甲方承擔。
3、甲方應在設計開始前提供完整的設計資料，由於甲方提供資料不完整、內容改動而造成的設
計結構改動，甲方須另行支付相應的設計改動費用。
4、乙方收到甲方的完整設計資料後進行部分小樣設計以方便甲方確定風格，風格確定後乙方開始進行初稿設計。
5、甲方有權對乙方所設計的作品提出修改意見，初稿甲方可提出一次結構上的修改，初稿確定後的結構修改，甲方須另行支付相應費用。
6、因甲方修改，延誤時間造成的後果，由甲方承擔。
7、由於後期製作造成的損失由甲方獨自承擔，由於製作物設計出現問題造成的損失由乙方承擔。 因著作權、文責所引發的法律責任，經濟糾紛由甲方承擔。
8、設計項目期間乙方掛靠於甲方品牌之中，不得以乙方身份單獨與客戶簽訂任何形式的合作協定。
五、智慧財產權約定：
1、乙方對設計完成的作品享有著作權。甲方將委託設計的所有費用結算完畢後，乙方可將作品著作權轉讓給甲方。
2、甲方在未付清所有委託設計費用之前，乙方設計的作品著作權歸乙方，甲方對該作品不享有任何權利。
3、甲方在餘款未付清之前擅自使用或者修改使用乙方設計的作品而導致的侵權，乙方有權追究其法律責任。
六、違約責任：
1、甲方在設計作品初稿完成前終止契約，其預付的費用無權要求退回；甲方在乙方作品初稿完成後終止契約的，應當支付全額的設計費用。
2、乙方如無正當理由提前終止契約，所收取的費用應當全部退回給甲方。
七、甲乙雙方如因履行本契約發生糾紛，應當友好協商解決，協商不成的，甲乙雙方任何一方均可向北京仲裁委員會提請仲裁解決。
八、本契約自甲乙雙方簽字蓋章之日起生效，本契約一式兩份，雙方各持對方簽字（蓋章）契約一份，具有同等的法律效力。
九、本契約如有未盡事宜，由甲乙雙方共同討論補充或修改。補充和修改的內容與本契約具有同等效力。
甲方： 乙方：
（簽字蓋章） （簽字蓋章）